West Virginia Sprinkler and Fire Protection Contractor (2018-07-01)

The provisions of this standard apply to the selection, installation, inspection, maintenance, and testing of portable extinguishing equipment. A.1.1 Many fires are small at origin and can be extinguished by the use of portable fire extinguishers. Notification of the fire department as soon as a fire is discovered is strongly recommended. This alarm should not be delayed by awaiting results of the application of portable fire extinguishers. Fire extinguishers can represent an important segment of any overall fire protection program.

1.1 Scope. 1.1.1 This standard covers the minimum requirements for the installation of standpipes and hose systems. 1.1.2* This standard does not cover requirements for periodic inspection, testing, and maintenance of these systems. A.1.1.2 See NFPA 25, Standard for the Inspection, Testing, and Maintenance of Water-Based Fire Protection Systems.

The provisions of this standard apply to the design, installation, operation, testing, and maintenance of pre-engineered wet chemical fire extinguishing systems that discharge wet chemical from fixed nozzles and piping by means of appellant gas. It contains only the essential requirements and recommendations needed to make the standard workable in the hands of those skilled in this field.

1.1 Scope. 1.1.1 This standard shall cover the minimum requirements for the installation of private fire service mains and their appurtenances supplying the following: (1) Automatic sprinkler systems (2) Open sprinkler systems (3) Water spray fixed systems (4) Foam systems (5) Private hydrants (6) Monitor nozzles or standpipe systems with reference to water supplies (7) Hose houses 1.1.2 This standard shall apply to combined service mains used to carry water for fire service and other uses. 1.1.3 This standard shall not apply to the following situations: (1) Mains under the control of a water utility (2) Mains providing fire protection and/or domestic water that are privately owned but are operated as a water utility 1.1.4 This standard shall not apply to underground mains serving sprinkler systems designed and installed in accordance with NFPA 13R that are under 4 in. (102 mm) in size. 1.1.5 This standard shall not apply to underground mains serving sprinkler systems designed and installed in accordance with NFPA 13D.

1.1 Scope. 1.1.1* This standard shall provide the minimum fire safety requirements (preventative and operative) related to the design, installation, operation, inspection, and maintenance of all public and private cooking operations. 1.1.2 This standard shall apply to residential cooking equipment used for commercial cooking operations. 1.1.3 This standard shall not apply to cooking equipment located in a single dwelling unit. 1.1.4* This standard shall not apply to facilities where all of the following are met: (1) Only residential equipment is being used. (2) Fire extinguishers are located in all kitchen areas in accordance with NFPA 10, Standard for Portable Fire Extinguishers. (3) The facility is not an assembly occupancy. (4) The authority having jurisdiction has approved the installation.

This standard shall cover the design and installation of automatic sprinkler systems for protection against fire hazards in residential occupancies up to and including four stories in height. 1.1.1 This standard assumes that the sprinkler system shall be designed to protect against a fire originating from a single ignition location.

This standard shall cover the design, installation, and maintenance of automatic sprinkler systems for protection against the fire hazards in one- and two-family dwellings and manufactured homes. 1.1.2 This standard assumes that the sprinkler system is designed to protect against a fire originating from a single ignition location.